Ntpc Mining Limited Grid Connected Roof Top Solar Power Plant Procurement Raigarh Chhattisgarh 2026
Bid Publish Date
06-Aug-2026, 5:45 pm
Bid End Date
20-Aug-2026, 1:00 pm
EMD
₹5,00,000
Location
Progress
Key Highlights
- • EMD amount: ₹5,00,000
- • Location: Raigarh, CHHATTISGARH 496001
- • Organization: Ntpc Mining Limited
- • Project scope: Grid Connected Roof Top Solar Power Plant with hybrid battery storage
- • Delivery model: Design, Supply, Installation, Commissioning and Maintenance (DSICM)
- • BOQ: 0 items implies turnkey/turnkey-style engagement
- • ATC terms: Buyer-uploaded ATC file governs technical/commercial compliance
- • No explicit technical specs in summary; relies on ATC for standards and performance criteria
Tender Overview
Ntpc Mining Limited invites bids for the design, supply, installation, commissioning and maintenance of a Grid Connected Roof Top Solar Power Plant with hybrid battery storage at Raigarh, CHHATTISGARH 496001. The scope references technical specification alignment and a formal ATC file; BOQ contains zero items, indicating a potentially project-wide design/build approach. The procurement location and solar scope define a strategic energy transition effort within the region. The bid includes an EMD of ₹5,00,000 and emphasizes compliance with the organization’s ATC terms, signaling stringent documentation and technical conformity expectations. The absence of BOQ items suggests a flexible, performance-based tender with emphasis on system integration, electrical safety, and grid compatibility.
Technical Specifications & Requirements
- Project focus: Grid Connected Roof Top Solar Power Plant with hybrid battery storage operating in Raigarh.
- Delivery scope: Design, Supply, Installation, Commissioning and Maintenance across the system lifecycle.
- Financials: EMD ₹5,00,000; no BOQ item count provided, implying a comprehensive turnkey solution.
- Documentation: Tender refers to an additional ATC file uploaded by the buyer; exact technical specs are not disclosed in the summary.
- Compliance expectations: System must align with NTPC Mining Limited standards and typical rooftop solar integration practices, including safety, grid synchronization, and long-term maintenance considerations.
Terms, Conditions & Eligibility
- Location: Raigarh, CHHATTISGARH 496001; organization: Ntpc Mining Limited.
- EMD: ₹5,00,000 (to accompany bid); ATC terms apply per buyer-specified conditions.
- BOQ: 0 items, indicating a turnkey design/installation approach subject to technical specifications in the ATC.
- Documentation: bids to conform with the buyer’s ATC, with emphasis on technical compliance, financial capability, and experience in solar rooftop projects.
- Timeline and penalties: not explicitly stated in the summary; bidders should verify ATC for delivery and penalty terms.
Key Specifications
-
Project: Grid Connected Roof Top Solar Power Plant with battery storage
-
Location: Raigarh, CHHATTISGARH (496001)
-
EMD: ₹5,00,000
-
BOQ: 0 items (indicative of turnkey engagement)
-
Documentation: ATC file governs technical/commercial requirements
Terms & Conditions
-
EMD of ₹5,00,000 required with bid submission
-
ATC terms uploaded by buyer govern technical compliance
-
Turnkey DSICM scope for rooftop solar with battery storage
Important Clauses
Payment Terms
Details to be defined in ATC; bidders should verify advance, milestone, and final payment conditions in the ATC document.
Delivery Schedule
Delivery and commissioning timelines will be specified in the ATC; prospective bidders must align project milestones with grid integration and safety standards.
Penalties/Liquidated Damages
LD clauses and penalties to be detailed in ATC; bidders should review for delays in DSICM deployment, testing, and commissioning milestones.
Bidder Eligibility
-
Experience in design/installation of grid-connected rooftop solar with battery storage
-
Capable to provide turnkey DSICM solutions with post-commissioning maintenance
-
Financial capability evidenced by turnover or statements per ATC requirements
Technical Results
| S.No | Seller | Date | Status |
|---|---|---|---|
| 1 | CLASSIC SIGNAGES PRIVATE LIMITED Under PMA | 20-08-2026 11:19:25 | |
| 2 | GCEP SOLAR PRIVATE LIMITED Under PMA | 20-08-2026 12:14:03 | |
| 3 | GOSOLAR POWER SYSTEMS Under PMA | 20-08-2026 12:08:05 | |
| 4 | INNOVEL ENERGY SERVICES PRIVATE LIMITED Under PMA | 18-08-2026 17:56:59 | |
| 5 | JUPISOL POWER INDIA PRIVATE LIMITED Under PMA | 19-08-2026 21:49:43 | |
| 6 | SPJ SOLAR TECHNOLOGY PRIVATE LIMITED Under PMA | 19-08-2026 12:56:58 | |
| 7 | STOCKWELL SOLAR SERVICES PRIVATE LIMITED Under PMA | 20-08-2026 12:55:39 | |
| 8 | SUVI AUTOMATION PRIVATE LIMITED Under PMA | 20-08-2026 08:28:13 | |
| 9 | WHITESHARK ENERGY PRIVATE LIMITED Under PMA | 20-08-2026 12:38:15 |
Financial Results
| Rank | Seller | Price | Item |
|---|---|---|---|
| L1 | WHITESHARK ENERGY PRIVATE LIMITED( MSE Social Category:General ) Under PMA | Item Categories : Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power | |
| L2 | STOCKWELL SOLAR SERVICES PRIVATE LIMITED Under PMA | Item Categories : Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power | |
| L3 | INNOVEL ENERGY SERVICES PRIVATE LIMITED( MSE Social Category:General ) Under PMA | Item Categories : Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power | |
| L4 | GCEP SOLAR PRIVATE LIMITED( MSE Social Category:General ) Under PMA | Item Categories : Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power | |
| L5 | GOSOLAR POWER SYSTEMS( MSE Social Category:General ) Under PMA | Item Categories : Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power | |
| L6 | SPJ SOLAR TECHNOLOGY PRIVATE LIMITED( MSE Social Category:General ) Under PMA | Item Categories : Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power | |
| L7 | CLASSIC SIGNAGES PRIVATE LIMITED( MSE Social Category:General ) Under PMA | Item Categories : Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power |
Contract / Result Documents 1
Please sign in or create an account to view contract details and download result documents.
Tender Data
Bid Details
Quantity
1
Bid Type
Two Packet Bid
Bid Validity
120 (Days)
Bid Type
Service
Evaluation
Total value wise evaluation
Tech Clarification Time
2 Days
Preference & Exemptions
EMD Required
Yes
MII Compliance
Yes
MSE Purchase Preference
Yes
MSE Preference Band
L1+15%
MSE Exemption/Relaxation
No
Startup Exemption/Relaxation
No
Bid Splitting Applied
No
Requirements
Arbitration Clause
No
Mediation Clause
No
Additional Tender Data
Commercial Details
Tender Category
Service
Bid To RA
No
Bid To RA Enabled
No
Item Category
Design, Supply, Installation, Commissioning and Maintenance of Grid Connected Roof Top Solar Power Plant Service - Hybrid with battery storage; As per technical specification; As per technical specification
Advisory Bank
ICICI
Payment Timelines
Payments shall be made to the Seller within 30 days of issue of service delivery acceptance certificate (SDAC) and on-line submission of bills (This is in supersession of 10 days time as provided in clause 12 of GeM GTC)
Delivery Details
Delivery Locations
1
Delivery Cities
Raigarh
Delivery Pincodes
496111
Delivery Locations
| Consignee | Address | City | State | Pincode | Quantity | Delivery Days | Additional Requirement |
|---|---|---|---|---|---|---|---|
| Narendra Guntupalli | 496111,NTPC Mining Ltd ,Talaipalli Coal Mining Projects, Lailunga Road, Gharghoda, Raigarh Chhattisgarh | Raigarh | Chhattisgarh | 496111 | Project / Lumpsum Based | - | - |
Authority Records
BID & GeM Expert Consultancy
End-to-end support — bid preparation, GeM registration, document filing & compliance by industry experts.
Free consultation · 24h response
Documents 4
GeM-Bidding-9719151.pdf
Main Document
Other Documents
OTHER
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
Categories
12
Corrigendum Updates
2 Updates Update
Update
Required Documents
GST registration certificate
PAN card
Experience certificates for solar rooftop design/installation projects
Financial statements or turnover proof (as per ATC requirements)
EMD submission proof (payment receipt or bank guarantee as specified in ATC)
Technical bid documents and compliance statements
OEM authorizations or system integrator certifications (as applicable in ATC)
Frequently Asked Questions
Key insights about CHHATTISGARH tender market
How to bid for Ntpc Mining Limited rooftop solar tender in Raigarh 2026?
Bidders must submit GST, PAN, and experience certificates, plus the EMD of ₹5,00,000 as per ATC. Ensure DSICM capability, OEM authorizations if required, and compliance with the uploaded ATC terms for technical specifications and payment schedule.
What documents are required for the Raigarh solar project bid 2026?
Required documents include GST registration, PAN, financial statements, past project experience certificates for rooftop solar with battery storage, EMD submission proof, and technical compliance documents as specified in the ATC uploaded by Ntpc Mining Limited.
What are the key technical standards for grid-connected rooftop solar bids in Chhattisgarh?
Standards will be detailed in the ATC file; bidders should expect grid synchronization, safety, and battery storage integration criteria, with potential IS/ISO conformity as per Ntpc Mining Limited requirements.
When is the bid submission deadline for the Raigarh solar DSICM tender 2026?
Deadline details are provided in the ATC uploaded by the buyer; bidders must consult the ATC for exact dates, submission portal requirements, and hard copy/document submission needs.
What is the EMD amount for the Ntpc Mining rooftop solar tender?
The EMD amount is ₹5,00,000; payments should follow the methods described in the ATC, typically via demand draft or online transfer with bid submission.
What is required to demonstrate eligibility for the solar DSICM project in Raigarh?
Demonstrate prior rooftop solar with battery storage experience, provide financial statements or turnover evidence per ATC, and supply technical compliance and OEM authorization documentation as specified.
How will penalties be applied for delays in the Raigarh solar project?
Penalties or LDs will be defined in the ATC; bidders should review the clause for milestones related to design, supply, installation, commissioning, and maintenance performance.
What makes this solar tender in Raigarh different from others?
This is a turnkey DSICM engagement for grid-connected rooftop solar with hybrid battery storage, with no BOQ items listed and ATC-defined technical and commercial criteria, emphasizing integration, safety, and long-term maintenance.