Indian Army Repair of Micro UAV Drishya Pro DPMK-II 291 Tender India 2026
Progress
Tender Overview
The Indian Army, Department Of Military Affairs, seeks repair services for the Micro UAV Drishya Pro DPMK-II 291. Scope encompasses repair, installation, testing, and commissioning of the UAV, with on-site inspection by the buyer. The bid requires the supplier to supply all required spares, components, and labour, and ensure completion with testing at the buyer’s location. The contract emphasizes post-repair testing in the presence of a buyer representative and a defined warranty period. No BOQ items are listed.
Technical Specifications & Requirements
- Product/Service: Repair of Micro UAV Drishya Pro DPMK-II 291; on-site repair and subsequent testing/commissioning.
- Warranty: Minimum 6 to 12 months warranty for repaired equipment.
- Scope: All spares, components, consumables, labour, testing; complete work including installation, testing, and commissioning by seller.
- Inspection: Conducted by buyer; SLBR52 noted as inspection reference.
- Payment Terms: 100% payment upon successful completion, installation, testing, and user inspection with a work completion certificate.
- Turnover Criteria: Bidder must meet minimum average annual turnover over last 3 years; documentation via audited statements or CA/Cost Accountant certificate.
- OEM/Support: For imported UAVs, OEM or authorized seller must have registered Indian office for after-sales service.
- Documents: All bid documents must be uploaded; duplicates rejected.
- Delivery/Scope of Supply: Includes supply, installation, testing, commissioning of goods; delivery at buyer’s premises.
Terms, Conditions & Eligibility
- Warranty Window: 6–12 months warranty mandatory for repair work.
- Pre-delivery Inspection: Buyer may reject defective parts; costs borne by vendor.
- Payment Milestones: 100% on successful completion, with a work completion certificate from user/inspection authority.
- Turnover Requirements: Bidder turnover to meet three-year average thresholds; provide certified audited balance sheets or CA certificate.
- OEM Eligibility: Imported UAVs require OEM/authenticated after-sales support in India; certificate to be submitted.
- Documentation: No duplicate uploads; all required documents must be included for evaluation.
Key Specifications
-
Product/Service: Repair, installation, testing and commissioning of Micro UAV Drishya Pro DPMK-II 291
-
Warranty: 6 to 12 months on repaired equipment
-
Inspection reference: SLBR52
-
Payment: 100% after successful completion and inspection with work completion certificate
-
Turnover: three-year average turnover requirement with audited statements or CA certificate
-
OEM: registered Indian office for imported UAV after-sales service
-
Documentation: single-upload rule, no duplicates
Terms & Conditions
-
EMD/financial guarantee: Not specified in data; ensure turnover and warranty compliance
-
Delivery/installation: Complete scope including testing at buyer’s site
-
Warranty/Penalties: 6–12 months warranty; defect rejection rights with transport costs on vendor
Important Clauses
Payment Terms
100% payment upon successful work completion, installation, testing, and inspection with work completion certificate.
Delivery Schedule
Scope includes supply, installation, testing, and commissioning at buyer's location; no specific dates provided.
Penalties/Liquidated Damages
No explicit LD figures stated; defects and non-conformities may be rejected with associated transport costs.
Bidder Eligibility
-
Minimum average annual turnover for last 3 years as per bid criteria
-
Experience in UAV repair or similar defense equipment within last 3–5 years
-
OEM authorization for imported UAVs or proof of Indian after-sales support
Tender Data
Bid Details
Quantity
1
Bid Type
Two Packet Bid
Bid Validity
120 (Days)
Bid Type
Service
Evaluation
Total value wise evaluation
Inspection Required
No
Tech Clarification Time
2 Days
Preference & Exemptions
EMD Required
No
MII Purchase Preference
No
MSE Purchase Preference
Yes
MSE Preference Band
L1+15%
MSE Exemption/Relaxation
No
Startup Exemption/Relaxation
No
Bid Splitting Applied
No
Requirements
Min. Avg. Annual Turnover
5
OEM Avg. Turnover
4
Past Performance
10 %
Experience Required
3 Year (s)
Arbitration Clause
No
Mediation Clause
No
Additional Tender Data
Commercial Details
Tender Category
Goods
Bid To RA
No
Bid To RA Enabled
No
Item Category
Repair of Micro UAV Drishya Pro DPMK-II 291
Delivery Details
Max Delivery Days
29
Delivery Locations
1
Delivery Cities
Dhemaji
Delivery Locations
| Consignee | Address | City | State | Pincode | Quantity | Delivery Days | Additional Requirement |
|---|---|---|---|---|---|---|---|
| - | Dhemaji | Dhemaji | - | - | 1 | 29 | - |
Authority Records
BID & GeM Expert Consultancy
End-to-end support — bid preparation, GeM registration, document filing & compliance by industry experts.
Free consultation · 24h response
Documents 3
GeM-Bidding-9889804.pdf
Main Document
Technical Specification/Buyer Specification Document
TECHNICAL
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
Corrigendum Updates
1 Update Update
Extended Deadline
01-Oct-2026, 4:30 am
Opening Date
02-Oct-2026, 4:30 am
🤖 AI-Powered Bidder Prediction
Discover companies most likely to bid on this tender
Required Documents
GST registration certificate
PAN card
Audited financial statements or CA certificate indicating turnover for last 3 years
Experience certificates for similar UAV repair projects
OEM authorization or authorised seller certificate (for imported UAVs)
Work completion certificate or reference from buyer for similar repairs
Technical bid documents and inspection reports
Any other documents specifically requested in the terms
Frequently Asked Questions
Key insights about ASSAM tender market
How to bid for UAV repair tender in India 2026
To bid, upload all required documents (GST, PAN, turnover certificates, OEM authorizations), ensure the UAV repair scope matches the bid, provide a 6–12 month warranty, and confirm 100% payment upon completion after buyer inspection and certification.
What documents are required for UAV repair tender submission in India
Submit GST certificate, PAN, three-year turnover audited statements, CA certificate, UAV repair experience certificates, OEM authorization for imported equipment, and the work completion certificate or reference from a similar project.
What are the key technical requirements for Drishya Pro UAV repair
The contract requires repair, installation, testing, and commissioning of Micro UAV Drishya Pro DPMK-II 291, with 6–12 months warranty; SLBR52 inspection reference; all spares and labor to be supplied by the contractor.
What are the payment terms for Indian Army UAV repair work
Payment is released as 100% after successful completion, installation, testing, and buyer inspection, with a work completion certificate issued by the user/inspection authority.
What is the warranty period for UAV repairs under this tender
A minimum warranty of 6 to 12 months is required for the repaired Micro UAV Drishya Pro DPMK-II 291, covering workmanship and replaced components as applicable.
Who qualifies as an OEM for imported UAVs in this tender
Imported UAVs require an OEM or authorized seller with a registered office in India to provide after-sales service; submit the certificate proving this arrangement.
What inspections are required during UAV repair bidding
Buyer reserves the right to inspect and reject defective parts; SLBR52 is noted as the inspection reference, and all replacement costs are borne by the vendor for rejected parts.