Balmer Lawrie Civil & Mechanical Works and Manpower Supply Obra Thermal Power Station Sonbhadra UP 2026 Tender
Bid Publish Date
23-Oct-2026, 6:03 pm
Bid End Date
12-Nov-2026, 7:00 pm
Location
Progress
Tender Overview
Balmer Lawrie And Company Limited invites bids for miscellaneous civil, mechanical work and manpower supply at the Obra Thermal Power Station, Sonbhadra, Uttar Pradesh (231205). The scope covers on-site civil/ mechanical services and manpower provisioning for ongoing works at a coal-fired plant. No BOQ items are listed, and the tender appears to be organized under the government-style procurement framework. The unique aspect is site-specific execution at a major power station, with integration into existing maintenance and civil works programs. This opportunity targets contractors with multi-discipline capabilities and the capacity to coordinate with a thermal plant environment.
Technical Specifications & Requirements
- Location: Obra Thermal Power Station, Sonbhadra, Uttar Pradesh
- Category: Custom Bid for Services - Miscellaneous Civil, Mechanical Work and Supply of Manpower
- Target scope: on-site civil and mechanical works plus manpower provisioning at a power plant
- BOQ items: 0 items listed; bidders should infer scope from tender terms and ATC document
- EMD/Financials: Not disclosed in available data; verify with ATC and procurement portal
- Key constraints: site access, safety, and coordination with plant operations; no explicit technical standards provided in the data
- Expected deliverables: workforce deployment, site civil/mechanical tasks, and project support at Obra TPS
- ATC/documents: Refer to Buyer Uploaded ATC for specific compliance and bid submission requirements
Terms, Conditions & Eligibility
- Organization: Balmer Lawrie And Company Limited, Uttar Pradesh site (Obra TPS, Sonbhadra)
- EMD: Not disclosed in the provided data; bidders must consult ATC for amount and payment method
- Delivery Timeline: Not specified in available data; bidders should review ATC for schedule and milestones
- Payment Terms: Not specified; verify in ATC terms and contractual documents
- Documents to Submit: GST, PAN, experience certificates, financials, EMD/Security, technical bid, OEM authorizations (per ATC)
- Warranty/Guarantees: Not specified in provided data; check ATC for post-award support terms
- Compliance: Follow site safety and plant operation protocols; align with Obra TPS requirements
- Penalties: Not disclosed; confirm LD or performance bonds in ATC
- Validity: Bid validity period to be confirmed in ATC; bidders must verify before submission
Key Specifications
-
Product/Service: Miscellaneous civil and mechanical works with manpower supply for a thermal power station
-
Location/Site: Obra Thermal Power Station, Sonbhadra, Uttar Pradesh
-
Estimated Value: Not disclosed in available data; verify in ATC
-
Standards/Certifications: Not specified; refer to ATC for required certifications
-
Delivery/Completion: Not specified; confirm with ATC and project schedule
-
Warranty/Support: Not specified; check ATC for AMC/maintenance terms
Terms & Conditions
-
EMD amount and payment method as per ATC
-
Delivery schedule and milestone commitments defined in ATC
-
Submission of GST, PAN, experience, financials and OEM authorizations
Important Clauses
Payment Terms
Terms to be confirmed in ATC; bidders must verify advance, milestone, or post-acceptance payments
Delivery Schedule
Project milestones and site deployment timelines to be detailed in ATC; bidders should align with Obra TPS operations
Penalties/Liquidated Damages
LDs to be specified in ATC; bidders must account for potential schedule or performance penalties
Bidder Eligibility
-
Experience in civil and mechanical works within power plant environments
-
Ability to supply/manpower and comply with site safety standards
-
Financial capacity to meet EMD and project obligations
Tender Data
Bid Details
Quantity
1
Similar Category
Maintenance and Pigging Service for Oil and Gas Pipelines Manpower Outsourcing Services - Minimum wage Repair, Maintenance and Installation of Plant/ Systems/Equipments
Bid Type
Two Packet Bid
Bid Validity
90 (Days)
Bid Type
Service
Evaluation
Total value wise evaluation
Tech Clarification Time
3 Days
Preference & Exemptions
EMD Required
Yes
MII Compliance
Yes
MSE Purchase Preference
Yes
MSE Preference Band
L1+15%
MSE Exemption/Relaxation
Yes
Startup Exemption/Relaxation
No
Bid Splitting Applied
No
Requirements
Min. Avg. Annual Turnover
616
Experience Required
7 Year (s)
Arbitration Clause
No
Mediation Clause
No
Additional Tender Data
Commercial Details
Tender Category
Service
Bid To RA
No
Bid To RA Enabled
No
Item Category
Custom Bid for Services - MISCELLANEOUS CIVIL MECHANICAL WORK AND SUPPLY OF MANPOWER AT OBRA THERMAL POWER STATION OBRA SONEBHADRA UTTAR PRADESH
Advisory Bank
AXIS BANK LTD
Payment Timelines
Payments shall be made to the Seller within 45 days of issue of service delivery acceptance certificate (SDAC) and on-line submission of bills (This is in supersession of 10 days time as provided in clause 12 of GeM GTC)
Delivery Details
Delivery Locations
1
Delivery Cities
Sonbhadra
Delivery Pincodes
231219
Delivery Locations
| Consignee | Address | City | State | Pincode | Quantity | Delivery Days | Additional Requirement |
|---|---|---|---|---|---|---|---|
| Mrinal Kanti Dawn | 231219,Balmer Lawrie & Co. Ltd., Obra Thermal Power Plant, Uttar Pradesh Rajya Vidyut Utpadan Nigam Limited (UPRVUNL), PO: Obra Thermal S.O. | Sonbhadra | Uttar Pradesh | 231219 | Project / Lumpsum Based | - | - |
Authority Records
BID & GeM Expert Consultancy
End-to-end support — bid preparation, GeM registration, document filing & compliance by industry experts.
Free consultation · 24h response
Documents 10
GeM-Bidding-10074286.pdf
Main Document
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
Other Documents
OTHER
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
GEM General Terms and Conditions Document
GEM_GENERAL_TERMS_AND_CONDITIONS
Categories
4
🤖 AI-Powered Bidder Prediction
Discover companies most likely to bid on this tender
Required Documents
GST Registration Certificate
Permanent Account Number (PAN) Card
Experience Certificates (civil, mechanical, manpower provisioning)
Financial Statements (last 2-3 years)
Earnest Money Deposit (EMD) documents as per ATC
Technical Bid Documents and Compliance Sheets
OEM Authorizations or Agency/Distributor Certificates (if applicable)
Any Safety/Quality Certifications referenced in ATC
Frequently Asked Questions
Key insights about UTTAR PRADESH tender market
How to bid for Balmer Lawrie Obra power plant tender
Bidders should review the ATC for exact EMD, submission documents, and site safety requirements. Prepare GST, PAN, experience certificates, financials, and OEM authorizations. Ensure manpower capability and adherence to site operations programs; submit technical and commercial bids through the specified portal by the ATC deadline.
What documents are required for this tender in UP
Required documents include GST registration, PAN, experience certificates in civil/mechanical works and manpower supply, financial statements, EMD documents, technical bid with compliance sheets, and OEM authorizations as detailed in the ATC.
What are the delivery requirements for Obra TPS works
Delivery requirements will be defined in the ATC; bidders must anticipate site deployment at Obra Thermal Power Station and align with plant safety protocols, with milestones and timelines specified in the same document.
What financial qualifications are needed for this tender
Submit up-to-date financial statements, demonstrate liquidity to cover EMD and initial mobilization, and provide turnover evidence relevant to civil, mechanical, and manpower service contracts as per ATC.
How to confirm EMD amount and mode of payment
EMD amount and payment mode (DD/online) will be detailed in the ATC. Prepare the exact sum and target date; ensure payment proof is submitted with the bid as per ATC instructions.
When is the submission deadline and bid validity
ATC will specify the submission deadline and bid validity period. Bidders should prepare and submit both technical and commercial bids before the stated date, ensuring validity aligns with ATC terms.
What safety standards or certifications are required
ATC may require plant-safety compliance and relevant certifications for civil/mechanical works and manpower, plus OEM authorizations. Confirm ISI, ISO, or client-specific standards in the ATC and ensure workforce meets safety training requirements.
How to verify BOQ items and scope for Obra works
BOQ shows 0 items in data; bidders must rely on ATC and tender terms for scope, site tasks, and integration with Obra TPS maintenance programs; request clarifications if needed before bid submission.